Party A (Employer): address: Business license number: contact number: Party B (contractor): Business license number: In accordance with the provisions of the "Contract Law of the People's Republic of China" and in conjunction with the specific circumstances of this project, Party A and Party B shall agree on the principle of voluntariness, equality, honesty, and trust, and jointly conclude the following terms so that both parties can jointly abide by it. The first project overview 1.1 Project Name: 1.2 Project location: 1.3 Projects and Contract Scope: For details, please refer to "Project Budget Book". 1.4 Project Content: For details, see the "Project Budget Book." 1.5 Contracting Method: Please refer to the "Project Budget Book" for details. 1.6 Construction Date: From the beginning of the year to the end of the year, the duration of the project is total. 1.7 Project Total: RMB Yuan (Lower: Yuan). The second contract for payment methods 2.1 On the date of signing this contract, Party A shall pay Party B the one-time payment of 30% of the total project cost and shall pay the provision money. Party B shall prepare the material within 3 days after the receipt of the provision and on the agreed start date (special material or change part of the project Except material) and construction machinery, and completed the entry construction procedure with Party A's assistance; Party A shall pay the construction money to Party B at a rate of 30% of the total project price before the painter enters the market; Party A will turn to Party B after the completion of the painter's work. The project payment shall be paid at a proportion of 30% of the total project cost; the remaining 10% of the balance of the decoration project shall be paid by Party A to Party B within 7 days from the date of acceptance by both parties. 2.2 As the project budget changes due to changes or additions of the project (contents), Party A shall sign the "Project Change Order". Therefore, the additional costs shall be paid to Party B within one (2) natural days after signing. 2.3 During the construction period, if Party A requires special requirements, Party B shall obtain Party B's prior approval when it finishes work earlier than the contract period; Party B shall pay Party B's early completion of work, and Party A shall pay Party B's corresponding expenses for the increase of the due-time. (The amount of fees shall be calculated according to the specific conditions of the project. Both parties will negotiate separately.) 2.4 During the construction process, if Party A does not pay the money in time according to the payment method stated above, Party B has the right to charge demurrage charges to Party A at a rate of 0.3% of the total project cost until Party A pays the bill; the payment time is delayed. For more than seven natural days, Party B has the right to terminate the contract unilaterally; Party A and Party B shall go through the project settlement procedures; Party B shall not refund the project money regardless of whether the project is completed or not; Party B has already completed the construction project and Party A has not paid the project payment. The Party B shall pay Party B’s project money according to the actual amount of work, and Party B’s losses shall be borne by Party B. 2.5 If the project after the completion of the transfer process fails to make timely payment in accordance with the agreed payment method, Party B has the right to charge delinquency to Party A at the rate of 1% of the final amount of the project, until Party A pays off. . 2.6 If the delay of construction due to non-Party A causes the project to fail to proceed according to the agreed schedule, the amount of the project payable by Party A may be deferred for payment as agreed by Party A and Party B according to the actual situation. 2.7 The project amount payable by Party A shall not be delivered to the non-contracted signer or the non-contracted signer. Otherwise, all the consequences arising therefrom shall be borne by Party A itself. Third schedule agreement 3.1 During the construction process, if Party A requests to modify individual design plans, Party B must notify Party B's construction management personnel and/or designers before the construction of the project is officially completed. Party B's designers must make modifications within 3 days after receiving the notice, and notify Party A of the plan. The party confirmed that the construction period caused by this delay was delayed and the construction period was postponed; 3.2 In the construction project, the decoration materials provided by Party A, Party B shall fill in Party A's Notice of Prepared Materials to Party A in advance to enable Party A to prepare the materials in time. After Party A receives the notice, it shall prepare according to the notice. Material; If Party A's preparation of materials is not timely or inaccurate, delays will be delayed and the duration of the project will be postponed. If Party B does not promptly notify Party A of the preparation of the materials or the contents of the notice are incorrect, Party A cannot delay the construction due to inaccurate and/or inaccurate materials. The construction period will not be postponed. 3.3 During the construction process, Party A has the right to stop the construction due to Party A failing to pay according to the payment method specified in the contract and delaying it for more than 7 natural days. Until Party A pays the amount, Party B will continue the construction, resulting in delay of the construction period. Postponed. 3.4 During the construction process, after the construction of the concealed project was completed, Party A failed to timely conduct inspection of the concealed project and required re-inspection after receiving the “project acceptance noticeâ€. The resulting schedule was delayed and the construction period was postponed. 3.5 Due to Party A's reasons, the time limit will be extended when the project volume and/or project changes are increased. 3.6 Due to delays in construction due to improper organization and construction by Party B, the construction period will not be postponed. 3.7 After the completion of the project, Party A proposes a rectification request, resulting in a delay in the construction period and a delay in the construction period. 3.8 Due to the delay of the construction period caused by Party A's property management department, the construction period was postponed. 3.9 Delays due to objective reasons such as water stoppages, blackouts, typhoons, and delays in construction schedules. 3.10 Due to delays in construction due to fire engineering and central air-conditioning engineering, the duration of the project will be postponed. 3.11 The terms of extension in the above terms caused delays in the duration of the contract. Party A and Party B did not pay the delay for the duration of the project. The delay in terms of the duration did not result in a delay in the duration of the contract. Party B paid the delay fee to Party A at a rate of 0.3% of the total project cost. Article 4 Changes in Project Items (Contents) 4.1 Before the formal construction of the contract is signed, if Party A requests to delete part of the project (contents), Party A and Party B must sign the “confirmation of the project (content) changeâ€; and Party A must reduce the total cost of the project. 2%, to pay the material preparation fee to Party B. 4.2 During the formal construction of the project, if Party A requests the deletion of part of the wooden construction project (contents), Party A and Party B shall sign the “confirmation form for the change of the project (content)â€; if the project is not planned, Party A shall delete the portion. The total construction cost is 2%. Party B shall pay Party B the material preparation fee; Party A shall pay the materials and labor costs to Party B according to 50% of the total construction cost of the project; if Party B has already completed the construction project, Party A shall press the project. 80% of the total cost, Party B shall pay Party B the material and labor costs. If the project has been completed, Party A shall pay Party B the material and labor costs in accordance with 100% of the total construction cost of the project. 4.3 During the formal construction process of the project, if Party A requests the deletion of some non-wood construction items (contents), Party A and Party B must sign the “Confirmation Form for the Change of Project Items (Contents)â€; Party A shall delete the unfinished project items. Part of the total construction cost is 2%. Party B shall pay Party B a material preparation fee; Party A shall pay the material and labor costs to Party B according to the specific loss limit of the cancelled project. Article 5 Project Quality and Acceptance Agreement 5.1 Party B shall purchase construction materials in accordance with the material quality standards set out in the “Project Budget†attached to this contract; Party A may determine the color and pattern of materials such as decorative veneer; and specify the materials purchased by Party B according to Acceptance by the Standard 5.2 Party B shall perform the construction according to the construction process and construction contents specified in the “Project Budget†attached to this contract. 5.3 Both Party A and Party B accepted the construction quality in accordance with the “Shanghai Construction Engineering Acceptance Criteriaâ€. 5.4 Acceptance of the completion project: After the construction of the project is completed, Party B shall issue a “project acceptance notice†to notify Party A to accept the acceptance of the completion project; Party A shall cooperate with Party B in the acceptance inspection of the completion project within 3 days after receiving the “project acceptance noticeâ€. Party cannot accept the acceptance of the completion project in time within the agreed time limit and is deemed to be qualified for acceptance for more than 7 natural days. After 3 days, Party A shall pay Party B's construction site care fee at 500 yuan/day; the completion acceptance shall be signed by Party A and Party B. "Project Completion Acceptance Form" and apply for project handover procedures. Article 6 Project Settlement Agreement 6.1 After completion of the project, Party B and Party B shall deliver the “Project Settlement Form†to Party A within 2 days after completing the transfer formalities. Party A shall pay all settlement amounts within 7 calendar days of acceptance of the project. 6.2 The contents of the project settlement include: construction settlement money, Party A's payment demurrage fees, and Party A's failure to accept and accept the construction site care costs incurred by Party B at Party B’s request; Party A requires Party B to finish the work ahead of schedule; Party B advances Party A’s ownership. The renovation deposit received by the property management department deducts the delay fee for Party B's construction period, and Party A pays the penalty for Party B's violation of Party A's property management department's relevant regulations during the construction period. 6.3 After Party A paid the settlement amount at the agreed time, Party B issued a project quality warranty. Article 7 Service Agreement 7.1 After the construction process and the completion of the project, Party B's "Quality Control Center - Customer Service Department" will perform project service management. 7.2 During the construction process, Party B’s affiliated staff collaborated with Party A to perform material shopping and material identification duties. 7.3 Upon completion of the settlement of the project, Party A shall issue the warranty statement, project settlement statement, and receipt voucher as proof of warranty. 7.4 Warranty Service Hours: 365 natural days from the date of completion of the project, ie one year. 7.5 Warranty Content and Warranty Scope: 7.5.1 Party B shall carry out all the free guarantees for the construction projects carried out by Party B in the form of contracted materials due to the quality problems caused by the materials used by Party B and improper construction processes; 7.5.2 Party B uses the quality of construction projects that are not included in the contract due to improper construction process of Party B. Party B implements all free warranty (including compensation for Party A's purchase of materials); 7.5.3 Party B uses the quality problems caused by Party A's use of improperly maintained and improperly maintained construction projects and Party B's construction projects carried out in the form of contracted and uncontained materials. Party B implements a paid warranty and Party B buys the goods. In the case of decoration materials, Party B shall collect materials and labor costs. Party A shall purchase the materials, and Party B shall collect labor fees. 7.5.4 If Party B's construction project exceeds the warranty period, Party A shall implement paid maintenance for Party A. The charge shall be: material fee and labor cost. Article 8 Other Conventions 8.1 This contract shall be legally effective after it has been signed by both parties. Before the terms of the contract are officially fulfilled, if either party to Party B terminates the contract unilaterally, it shall compensate the other party according to 2% of the total contract budget. 8.2 After the signing of the contract, if the construction project (contents) stipulated in this contract is approved by Party B and the deletion procedures are handled in accordance with the relevant provisions, if Party A arranges the construction separately, the construction shall not be carried out simultaneously during the performance period of the contract. 8.3 During the implementation of this contract, if for any reason the contract cannot be performed, it shall promptly notify the other party and complete the contract termination settlement procedure. If the contractor causes losses, he shall be compensated. 8.4 After the signing of the contract, Party A shall arrange for Party B's construction work (contents) in the contract other than the third party's construction. If Party B carries out the construction within this contract, Party A must pay Party B's corresponding construction fee, Party B's construction. Item (content) Finished product protection fee (agreed specific agreement); Otherwise, the related consequences arising therefrom shall be borne by Party A itself. 8.5 During the construction period, Party B shall be responsible for the water, electricity, and gas costs incurred by Party B for the construction site. 8.6 During the construction period, Party B shall not use the fire at the construction site or use the electric stove for cooking or heating. 8.7 During the construction period, Party B shall be responsible for all the responsibilities caused by Party B's improper construction operations, or the occurrence of fire or the use of electric furnace at the construction site, and all the disasters and personal injuries. 8.8 After the construction is completed, Party B shall clean the construction site. 8.9 As a result of force majeure events on the implementation of the contract will have a certain impact, according to different degrees, Party A and Party B negotiated rescind the contract, part of the performance of the contract, the extension of the performance of the contract. Article 9 Dispute Resolution Agreement 9.1 Disputes related to the validity, performance, breach of contract and cancellation of this contract shall be settled through friendly negotiations between both parties. 9.2 If the negotiation between the two parties fails, both parties may choose the following method to resolve the dispute: 9.2.1 apply to Shanghai Arbitration Commission for arbitration; 9.2.2 Proceeding to the people's court in the place where the contract is signed shall be determined by the court. Article 10 Supplementary Provisions 10.1 This contract is made in two copies. Each party holds one copy and has the same legal effect. Both parties shall observe the same. 10.2 The matters not covered in this contract are negotiated between the parties. Party A: Party B: XX Engineering Co., Ltd. Representative: Representative: Date of signing: Date of signing: Signing Location: Signing Location: Construction Contract Decoration Decoration Paint Decoration Company Central Air Conditioning
Diesel nozzle tester is a basic tool for a diesel injection service lab.
Manual nozzle tester is also know as pop tester, used to test mechanical injector, or test common rail electronic injector by cooperate with a simulator.
Diesel injector nozzle tester is used to calibrate the injection nozzle opening pressure, check leakage, check fuel spray pattern etc.
Nozzle Tester,Injector Nozzle Tester,Diesel Injector Nozzle Tester,Diesel Nozzle Tester CHENGDU UNICO MACHINERY CO., LTD , https://www.injectortestbench.com